This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotes are being requested and a written solicitation will not be issued. The details of this procurement are located below and in the attached specifications.

The solicitation number for this requirement is SP4510-18-Q-1039 and will be issued as a Request for Quote (RFQ). The solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 2005-61. This procurement is being set aside 100% for HUBZone small business concerns under NAICS 238910, which has a size standard of $15,000,000.00. .

A. The provision at FAR 52.212-1 (Instructions to Offerors -- Commercial) applies to this procurement.

B. The provision at FAR 52.212-2 (Evaluation -- Commercial Items) applies to this procurement. The Government will award a contract resulting from this solicitation to the offeror that has the lowest price and that is technically acceptable.

C. In accordance with FAR 52.212-3 (Offerors Representations and Certifications -- Commercial Items) the contractor shall ensure that it has completed the annual representations and certifications on SAM.gov or submit a completed copy of the provision at FAR 52.212-3 with its offer.

D. FAR 52.212-4 (Contract Terms and Conditions -- Commercial Items) applies to this procurement.

E. FAR 52.212-5 (Contract Terms and Conditions Required to Implement Statutes or Executive Orders --Commercial Items) applies to this procurement. The additional FAR clauses which are cited in FAR 52.212-5 are listed here:

SECTION D -

PACKAGING AND MARKING 52.211-9033 PACKAGING AND MARKING REQUIREMENTS (APR 2008) DLAD

SECTION E -

INSPECTION AND ACCEPTANCE 52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996) FAR

SECTION F -

DELIVERIES OR PERFORMANCE 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984), ALT I (APR 1984) FAR

52.211-12 LIQUIDATED DAMAGES - CONSTRUCTION (SEP 2000) FAR

52.211-13 TIME EXTENSIONS (SEP 2000)

FAR 52.242-14 SUSPENSION OF WORK (APR 1984)

FAR 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

FAR 52.247-34 F.O.B. DESTINATION (NOV 1991) FAR

SECTION G - CONTRACT ADMINISTRATION DATA

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013) DFARS

SECTION I - CONTRACT CLAUSES

252.201-7000 CONTRACTING OFFICER'S REPRESENTATIVE (DEC 1991) DFARS

252.203-7000 REQUIREMENTS RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (SEP 2011) DFARS

252.203-7002 REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (SEP 2013) DFARS

52.204-09 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (JAN 2011) FAR

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS (JUL 2013) FAR

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (JUL 2013) FAR

252.204-7003 CONTROL OF GOVERNMENT PERSONNEL WORK PRODUCT (APR 1992) DFARS

252.204-7004 ALTERNATE A, SYSTEM FOR AWRD MANAGEMENT (FEB 2014) DFARS

252.204-7012 SAFEGUARDING OF UNCLASSIFIED CONTROLLED TECHNICAL INFORMATION (NOV 2013) DFARS

52.209-06 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR SUSPENSION (AUG 2013) FAR

52.215-08 ORDER OF PRECEDENCE - UNIFORM CONTRACT FORMAT (OCT 1997) FAR

52.219-03 NOTICE OF HUBZONE SET-ASIDE OR SOLE SOURCE AWARD (NOV 2011) FAR

52.219-28 POST 52.222-03 CONVICT LABOR (JUN 2003) FAR

52.222-06 DAVIS-BACON ACT (JUL 2005) FAR

52.222-07 WITHHOLDING OF FUNDS (FEB 1988) FAR

52.222-08 PAYROLLS AND BASIC RECORDS (JAN 2010) FAR

52.222-09 APPRENTICES AND TRAINEES (JUL 2005) FAR

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988) FAR

52.222-11 SUBCONTRACTS (LABOR STANDARDS) (JUL 2005) FAR

52.222-12 CONTRACT TERMINATION - DEBARMENT (FEB 1988) FAR

52.222-13 COMPLIANCE WITH DAVIS-BACON AND RELATED ACT REGULATIONS (FEB 1988) FAR

52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988) FAR

52.222-15 CERTIFICATION OF ELIGIBILITY (FEB 1988) FAR

52.222-19 CHILD LABOR - COOPERATION WITH AUTHORITIES AND REMEDIES (JAN 2014) FAR

52.222-21 PROHIBITION OF SEGREGATED FACILITIES (FEB 1999) FAR

52.222-26 EQUAL OPPORTUNITY (MAR 2007) FAR

52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION (FEB 1999) FAR

52.222-36 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (JUL 2014) FAR

52.222-50 COMBATTING TRAFFICKING IN PERSONS (FEB 2009) FAR

52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE DRIVING (AUG 2011) FAR

52.225-09 BUY AMERICAN ACT - CONSTRUCTION MATERIALS (SEP 2010) FAR

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUN 2008) FAR

52.228-02 ADDITIONAL BOND SECURITY (OCT 1997) FAR

52.232-05 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (SEP 2002) FAR

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (OCT 2008) FAR

252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS (JUN 2012) DFARS

252.232-7010 LEVIES ON CONTRACT PAYMENTS (DEC 2006) DFARS

52.233-01 DISPUTES (MAY 2014) FAR

52.233-03 PROTEST AFTER AWARD (AUG 1996) FAR

52.233-04 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004) FAR

52.233-9001 DISPUTES - AGREEMENT TO USE ALTERNATIVE DISPUTE RESOLUTION (NOV 2011) DLAD

52.236-03 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984) FAR

52.236-05 MATERIAL AND WORKMANSHIP (APR 1984) FAR

52.236-07 PERMITS AND RESPONSIBILITIES (NOV 1991) FAR

52.236-08 OTHER CONTRACTS (APR 1984) FAR

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984) FAR

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984) FAR

52.236-12 CLEANING UP (APR 1984) FAR

52.236-13 ACCIDENT PREVENTION (NOV 1991) FAR

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984) FAR

52.243-01 CHANGES - FIXED PRICE (AUG 1987) FAR

52.243-05 CHANGES AND CHANGED CONDITIONS (APR 1984) FAR

252.243-7001 PRICING OF CONTRACT MODIFICATIONS (DEC 1991) DFARS

52.244-06 SUBCONTRACTS FOR COMMERCIAL ITEMS (OCT 2014) FAR

52.249-01 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (SHORT FORM) (APR 1984) FAR

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984) FAR

52.252-02 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) FAR

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUL 2013) (FAR)

52.204-08 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2014) FAR

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (AUG 2014) DFARS

252.203-7005 REPRESENTATION RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (NOV 2011) DFARS

52.204-07 SYSTEM FOR AWARD MANAGEMENT (JUL 2013) FAR

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999) FAR

52.225-10 NOTICE OF BUY AMERICAN ACT REQUIREMENT - CONSTRUCTION MATERIALS (FEB 2009) FAR

52.233-9000 AGENCY PROTESTS (NOV 2011) DLAD

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) FAR

52.252-01 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998) - FAR

INSTRUCTIONS TO OFFERORS:

Submit quotes by email to: [email protected] no later than August 3,, 2018 at 10:00 p.m.

Eastern Time. Attention should be noted to FAR 52.212-1(f), concerning late submissions. The offeror bears the risk of non-receipt of any email transmissions, and should ensure that all pages of the quote have been received by the designated office before the deadline indicated.

Offerors shall provide the applicable CAGE code and DUNS number with their bid submission. The information located in FAR 52.212-3 (Offerors Representations and Certifications) shall be current on SAM.gov at the time of quote submission.

Any solicitation questions shall be submitted no later than July 27, 2018. In the event questions are received, a solicitation amendment will be posted before the quote submission deadline